[2005] UGCommC 3

{\rtf1\adeflang1025\ansi\ansicpg1252\uc1\adeff0\deff0\stshfdbch0\stshfloch0\stshfhich0\stshfbi0\deflang1033\deflangfe1033\themelang1033\themelangfe0\themelangcs0{\fonttbl{\f0\fbidi \froman\fcharset0\fprq2{\*\panose 02020603050405020304}Times New Roman;}{\f34\fbidi \froman\fcharset0\fprq2{\*\panose 02040503050406030204}Cambria Math;} {\flomajor\f31500\fbidi \froman\fcharset0\fprq2{\*\panose 02020603050405020304}Times New Roman;}{\fdbmajor\f31501\fbidi \froman\fcharset0\fprq2{\*\panose 02020603050405020304}Times New Roman;} {\fhimajor\f31502\fbidi \froman\fcharset0\fprq2{\*\panose 02040503050406030204}Cambria;}{\fbimajor\f31503\fbidi \froman\fcharset0\fprq2{\*\panose 02020603050405020304}Times New Roman;} {\flominor\f31504\fbidi \froman\fcharset0\fprq2{\*\panose 02020603050405020304}Times New Roman;}{\fdbminor\f31505\fbidi \froman\fcharset0\fprq2{\*\panose 02020603050405020304}Times New Roman;} {\fhiminor\f31506\fbidi \fswiss\fcharset0\fprq2{\*\panose 020f0502020204030204}Calibri;}{\fbiminor\f31507\fbidi \froman\fcharset0\fprq2{\*\panose 02020603050405020304}Times New Roman;}{\f183\fbidi \froman\fcharset238\fprq2 Times New Roman CE;} {\f184\fbidi \froman\fcharset204\fprq2 Times New Roman Cyr;}{\f186\fbidi \froman\fcharset161\fprq2 Times New Roman Greek;}{\f187\fbidi \froman\fcharset162\fprq2 Times New Roman Tur;}{\f188\fbidi \froman\fcharset177\fprq2 Times New Roman (Hebrew);} {\f189\fbidi \froman\fcharset178\fprq2 Times New Roman (Arabic);}{\f190\fbidi \froman\fcharset186\fprq2 Times New Roman Baltic;}{\f191\fbidi \froman\fcharset163\fprq2 Times New Roman (Vietnamese);}{\f523\fbidi \froman\fcharset238\fprq2 Cambria Math CE;} {\f524\fbidi \froman\fcharset204\fprq2 Cambria Math Cyr;}{\f526\fbidi \froman\fcharset161\fprq2 Cambria Math Greek;}{\f527\fbidi \froman\fcharset162\fprq2 Cambria Math Tur;}{\f530\fbidi \froman\fcharset186\fprq2 Cambria Math Baltic;} {\flomajor\f31508\fbidi \froman\fcharset238\fprq2 Times New Roman CE;}{\flomajor\f31509\fbidi \froman\fcharset204\fprq2 Times New Roman Cyr;}{\flomajor\f31511\fbidi \froman\fcharset161\fprq2 Times New Roman Greek;} {\flomajor\f31512\fbidi \froman\fcharset162\fprq2 Times New Roman Tur;}{\flomajor\f31513\fbidi \froman\fcharset177\fprq2 Times New Roman (Hebrew);}{\flomajor\f31514\fbidi \froman\fcharset178\fprq2 Times New Roman (Arabic);} {\flomajor\f31515\fbidi \froman\fcharset186\fprq2 Times New Roman Baltic;}{\flomajor\f31516\fbidi \froman\fcharset163\fprq2 Times New Roman (Vietnamese);}{\fdbmajor\f31518\fbidi \froman\fcharset238\fprq2 Times New Roman CE;} {\fdbmajor\f31519\fbidi \froman\fcharset204\fprq2 Times New Roman Cyr;}{\fdbmajor\f31521\fbidi \froman\fcharset161\fprq2 Times New Roman Greek;}{\fdbmajor\f31522\fbidi \froman\fcharset162\fprq2 Times New Roman Tur;} {\fdbmajor\f31523\fbidi \froman\fcharset177\fprq2 Times New Roman (Hebrew);}{\fdbmajor\f31524\fbidi \froman\fcharset178\fprq2 Times New Roman (Arabic);}{\fdbmajor\f31525\fbidi \froman\fcharset186\fprq2 Times New Roman Baltic;} {\fdbmajor\f31526\fbidi \froman\fcharset163\fprq2 Times New Roman (Vietnamese);}{\fhimajor\f31528\fbidi \froman\fcharset238\fprq2 Cambria CE;}{\fhimajor\f31529\fbidi \froman\fcharset204\fprq2 Cambria Cyr;} {\fhimajor\f31531\fbidi \froman\fcharset161\fprq2 Cambria Greek;}{\fhimajor\f31532\fbidi \froman\fcharset162\fprq2 Cambria Tur;}{\fhimajor\f31535\fbidi \froman\fcharset186\fprq2 Cambria Baltic;} {\fbimajor\f31538\fbidi \froman\fcharset238\fprq2 Times New Roman CE;}{\fbimajor\f31539\fbidi \froman\fcharset204\fprq2 Times New Roman Cyr;}{\fbimajor\f31541\fbidi \froman\fcharset161\fprq2 Times New Roman Greek;} {\fbimajor\f31542\fbidi \froman\fcharset162\fprq2 Times New Roman Tur;}{\fbimajor\f31543\fbidi \froman\fcharset177\fprq2 Times New Roman (Hebrew);}{\fbimajor\f31544\fbidi \froman\fcharset178\fprq2 Times New Roman (Arabic);} {\fbimajor\f31545\fbidi \froman\fcharset186\fprq2 Times New Roman Baltic;}{\fbimajor\f31546\fbidi \froman\fcharset163\fprq2 Times New Roman (Vietnamese);}{\flominor\f31548\fbidi \froman\fcharset238\fprq2 Times New Roman CE;} {\flominor\f31549\fbidi \froman\fcharset204\fprq2 Times New Roman Cyr;}{\flominor\f31551\fbidi \froman\fcharset161\fprq2 Times New Roman Greek;}{\flominor\f31552\fbidi \froman\fcharset162\fprq2 Times New Roman Tur;} {\flominor\f31553\fbidi \froman\fcharset177\fprq2 Times New Roman (Hebrew);}{\flominor\f31554\fbidi \froman\fcharset178\fprq2 Times New Roman (Arabic);}{\flominor\f31555\fbidi \froman\fcharset186\fprq2 Times New Roman Baltic;} {\flominor\f31556\fbidi \froman\fcharset163\fprq2 Times New Roman (Vietnamese);}{\fdbminor\f31558\fbidi \froman\fcharset238\fprq2 Times New Roman CE;}{\fdbminor\f31559\fbidi \froman\fcharset204\fprq2 Times New Roman Cyr;} {\fdbminor\f31561\fbidi \froman\fcharset161\fprq2 Times New Roman Greek;}{\fdbminor\f31562\fbidi \froman\fcharset162\fprq2 Times New Roman Tur;}{\fdbminor\f31563\fbidi \froman\fcharset177\fprq2 Times New Roman (Hebrew);} {\fdbminor\f31564\fbidi \froman\fcharset178\fprq2 Times New Roman (Arabic);}{\fdbminor\f31565\fbidi \froman\fcharset186\fprq2 Times New Roman Baltic;}{\fdbminor\f31566\fbidi \froman\fcharset163\fprq2 Times New Roman (Vietnamese);} {\fhiminor\f31568\fbidi \fswiss\fcharset238\fprq2 Calibri CE;}{\fhiminor\f31569\fbidi \fswiss\fcharset204\fprq2 Calibri Cyr;}{\fhiminor\f31571\fbidi \fswiss\fcharset161\fprq2 Calibri Greek;}{\fhiminor\f31572\fbidi \fswiss\fcharset162\fprq2 Calibri Tur;} {\fhiminor\f31575\fbidi \fswiss\fcharset186\fprq2 Calibri Baltic;}{\fbiminor\f31578\fbidi \froman\fcharset238\fprq2 Times New Roman CE;}{\fbiminor\f31579\fbidi \froman\fcharset204\fprq2 Times New Roman Cyr;} {\fbiminor\f31581\fbidi \froman\fcharset161\fprq2 Times New Roman Greek;}{\fbiminor\f31582\fbidi \froman\fcharset162\fprq2 Times New Roman Tur;}{\fbiminor\f31583\fbidi \froman\fcharset177\fprq2 Times New Roman (Hebrew);} {\fbiminor\f31584\fbidi \froman\fcharset178\fprq2 Times New Roman (Arabic);}{\fbiminor\f31585\fbidi \froman\fcharset186\fprq2 Times New Roman Baltic;}{\fbiminor\f31586\fbidi \froman\fcharset163\fprq2 Times New Roman (Vietnamese);}} {\colortbl;\red0\green0\blue0;\red0\green0\blue255;\red0\green255\blue255;\red0\green255\blue0;\red255\green0\blue255;\red255\green0\blue0;\red255\green255\blue0;\red255\green255\blue255;\red0\green0\blue128;\red0\green128\blue128;\red0\green128\blue0; \red128\green0\blue128;\red128\green0\blue0;\red128\green128\blue0;\red128\green128\blue128;\red192\green192\blue192;}{\*\defchp \fs22 }{\*\defpap \ql \li0\ri0\sa200\sl276\slmult1\widctlpar\wrapdefault\aspalpha\aspnum\faauto\adjustright\rin0\lin0\itap0 } \noqfpromote {\stylesheet{\ql \li0\ri0\widctlpar\wrapdefault\aspalpha\aspnum\faauto\adjustright\rin0\lin0\itap0 \rtlch\fcs1 \af0\afs24\alang1025 \ltrch\fcs0 \fs24\lang1033\langfe1033\cgrid\langnp1033\langfenp1033 \snext0 \sqformat \spriority0 Normal;}{\* \cs10 \additive \ssemihidden Default Paragraph Font;}{\* \ts11\tsrowd\trftsWidthB3\trpaddl108\trpaddr108\trpaddfl3\trpaddft3\trpaddfb3\trpaddfr3\trcbpat1\trcfpat1\tblind0\tblindtype3\tscellwidthfts0\tsvertalt\tsbrdrt\tsbrdrl\tsbrdrb\tsbrdrr\tsbrdrdgl\tsbrdrdgr\tsbrdrh\tsbrdrv \ql \li0\ri0\sa200\sl276\slmult1 \widctlpar\wrapdefault\aspalpha\aspnum\faauto\adjustright\rin0\lin0\itap0 \rtlch\fcs1 \af0\afs22\alang1025 \ltrch\fcs0 \fs22\lang1033\langfe1033\cgrid\langnp1033\langfenp1033 \snext11 \ssemihidden \sunhideused \sqformat Normal Table;}{ \s15\ql \li0\ri0\sb100\sa100\sbauto1\saauto1\widctlpar\wrapdefault\aspalpha\aspnum\faauto\adjustright\rin0\lin0\itap0 \rtlch\fcs1 \af0\afs24\alang1025 \ltrch\fcs0 \fs24\lang1033\langfe1033\cgrid\langnp1033\langfenp1033 \sbasedon0 \snext15 \styrsid16350512 Normal (Web);}}{\*\pgptbl {\pgp\ipgp0\itap0\li0\ri0\sb0\sa0}}{\*\rsidtbl \rsid726520\rsid1454226\rsid4073394\rsid6384804\rsid7866645\rsid8395441\rsid9505340\rsid14699627\rsid16350512}{\mmathPr\mmathFont34\mbrkBin0 \mbrkBinSub0\msmallFrac0\mdispDef1\mlMargin0\mrMargin0\mdefJc1\mwrapIndent1440\mintLim0\mnaryLim1}{\info{\title THE REPUBLIC OF UGANDA }{\author Administrator}{\operator skivumbi}{\creatim\yr2010\mo3\dy12\hr12\min40}{\revtim\yr2010\mo6\dy4\hr12\min48} {\version5}{\edmins19}{\nofpages10}{\nofwords3322}{\nofchars16290}{\nofcharsws19573}{\vern32859}}{\*\xmlnstbl {\xmlns1 http://schemas.microsoft.com/office/word/2003/wordml}}\paperw12240\paperh15840\margl1440\margr1440\margt1440\margb1440\gutter0\ltrsect \widowctrl\ftnbj\aenddoc\trackmoves1\trackformatting1\donotembedsysfont0\relyonvml0\donotembedlingdata1\grfdocevents0\validatexml0\showplaceholdtext0\ignoremixedcontent0\saveinvalidxml0\showxmlerrors0\noxlattoyen \expshrtn\noultrlspc\dntblnsbdb\nospaceforul\formshade\horzdoc\dgmargin\dghspace180\dgvspace180\dghorigin1440\dgvorigin1440\dghshow1\dgvshow1 \jexpand\viewkind1\viewscale100\pgbrdrhead\pgbrdrfoot\splytwnine\ftnlytwnine\htmautsp\nolnhtadjtbl\useltbaln\alntblind\lytcalctblwd\lyttblrtgr\lnbrkrule\nobrkwrptbl\snaptogridincell\allowfieldendsel\wrppunct \asianbrkrule\rsidroot16350512\newtblstyruls\nogrowautofit \fet0{\*\wgrffmtfilter 2450}\ilfomacatclnup0\ltrpar \sectd \ltrsect\linex0\endnhere\sectlinegrid360\sectdefaultcl\sectrsid9505340\sftnbj {\*\pnseclvl1\pnucrm\pnstart1\pnindent720\pnhang {\pntxta .}}{\*\pnseclvl2\pnucltr\pnstart1\pnindent720\pnhang {\pntxta .}}{\*\pnseclvl3\pndec\pnstart1\pnindent720\pnhang {\pntxta .}}{\*\pnseclvl4\pnlcltr\pnstart1\pnindent720\pnhang {\pntxta )}}{\*\pnseclvl5\pndec\pnstart1\pnindent720\pnhang {\pntxtb (} {\pntxta )}}{\*\pnseclvl6\pnlcltr\pnstart1\pnindent720\pnhang {\pntxtb (}{\pntxta )}}{\*\pnseclvl7\pnlcrm\pnstart1\pnindent720\pnhang {\pntxtb (}{\pntxta )}}{\*\pnseclvl8\pnlcltr\pnstart1\pnindent720\pnhang {\pntxtb (}{\pntxta )}}{\*\pnseclvl9 \pnlcrm\pnstart1\pnindent720\pnhang {\pntxtb (}{\pntxta )}}\pard\plain \ltrpar\s15\qc \li0\ri0\sb100\sa240\sbauto1\sl360\slmult1\widctlpar\wrapdefault\aspalpha\aspnum\faauto\adjustright\rin0\lin0\itap0\ipgp1\pararsid726520 \rtlch\fcs1 \af0\afs24\alang1025 \ltrch\fcs0 \fs24\lang1033\langfe1033\cgrid\langnp1033\langfenp1033 {\rtlch\fcs1 \ab\af0 \ltrch\fcs0 \b\insrsid16350512\charrsid726520 THE REPUBLIC OF UGANDA \line IN THE HIGH COURT OF UGANDA A}{\rtlch\fcs1 \ab\af0 \ltrch\fcs0 \b\insrsid726520 T KAMPALA \line COMMERCIAL DIVISION \par }{\rtlch\fcs1 \ab\af0 \ltrch\fcs0 \b\insrsid16350512\charrsid726520 HIGH CO}{\rtlch\fcs1 \ab\af0 \ltrch\fcs0 \b\insrsid726520 URT CIVIL SUIT NO. 425 OF 2002 \par }{\rtlch\fcs1 \ab\af0 \ltrch\fcs0 \b\insrsid16350512\charrsid726520 M. H. CONSTRUCTION CO}{\rtlch\fcs1 \ab\af0 \ltrch\fcs0 \b\insrsid7866645\charrsid7866645 }{\rtlch\fcs1 \ab\af0 \ltrch\fcs0 \b\insrsid7866645\charrsid726520 LTD}{\rtlch\fcs1 \ab\af0 \ltrch\fcs0 \b\insrsid7866645 }{\rtlch\fcs1 \ab\af0 \ltrch\fcs0 \b\insrsid726520 \'85}{\rtlch\fcs1 \ab\af0 \ltrch\fcs0 \b\insrsid7866645 \'85.}{\rtlch\fcs1 \ab\af0 \ltrch\fcs0 \b\insrsid726520 \'85\'85\'85\'85\'85\'85\'85\'85\'85\'85\'85\'85\'85\'85\'85 ..}{\rtlch\fcs1 \ab\af0 \ltrch\fcs0 \b\insrsid16350512\charrsid726520 PLAINTIFF \line VERSUS \line PETRO UGANDA LTD }{\rtlch\fcs1 \ab\af0 \ltrch\fcs0 \b\insrsid726520 \'85\'85\'85\'85\'85\'85\'85\'85\'85\'85\'85..\'85\'85\'85\'85\'85\'85\'85\'85\'85..}{ \rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 . }{\rtlch\fcs1 \ab\af0 \ltrch\fcs0 \b\insrsid726520 DEFENDANT \par }\pard \ltrpar\s15\ql \li0\ri0\sb100\sa240\sbauto1\sl360\slmult1\widctlpar\wrapdefault\aspalpha\aspnum\faauto\adjustright\rin0\lin0\itap0\ipgp1\pararsid726520 {\rtlch\fcs1 \ab\af0 \ltrch\fcs0 \b\insrsid16350512\charrsid726520 Before: The }{\rtlch\fcs1 \ab\af0 \ltrch\fcs0 \b\insrsid726520 Hon. Mr. Justice E. S. Lugayizi \par }\pard \ltrpar\s15\qc \li0\ri0\sb100\sa240\sbauto1\sl360\slmult1\widctlpar\wrapdefault\aspalpha\aspnum\faauto\adjustright\rin0\lin0\itap0\ipgp1\pararsid726520 {\rtlch\fcs1 \ab\af0 \ltrch\fcs0 \b\insrsid16350512\charrsid726520 JUDGMENT}{\rtlch\fcs1 \ab\af0 \ltrch\fcs0 \b\insrsid726520 \par }\pard \ltrpar\s15\qj \li0\ri0\sl360\slmult1\widctlpar\wrapdefault\aspalpha\aspnum\faauto\adjustright\rin0\lin0\itap0\ipgp1\pararsid726520 {\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 This judgment is in respect of a suit the plaintiff filed against the defendant seekin}{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid726520 g Court\rquote s remedies as follows: \par }{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 1. Payment of a sum of shillings 37}{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid726520 ,667,730/= as special damages. \par }{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 2. General d}{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid726520 amages for breach of contract. \par }{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 3. Interest on the items in paragraphs 1 and 2 above at 36% per annum from the date of filing }{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid726520 the suit till payment in full. \par 4. Costs of the suit. \par }\pard \ltrpar\s15\qj \li0\ri0\sb100\sa240\sbauto1\sl360\slmult1\widctlpar\wrapdefault\aspalpha\aspnum\faauto\adjustright\rin0\lin0\itap0\ipgp1\pararsid726520 {\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 In its Written Statement of Defence the defendant denied the above claim and averred that the plaintiff was not entitled to any of the remedies it is claiming because it breached the contract. It then counter-claimed against the plaintiff for a penalty of shillings lm/ every day of default, general damages for breach of contract a}{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid726520 nd costs of the counter-claim. \par }{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 At the Scheduling Conference the parties agreed to admit the following facts: \par 1. That there was a contract between the plaintiff and the defendant dated l9\'94 November 2001 wherein the plaintiff undertook to construct a petrol station for the defendant at Plot 34 Block }{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid726520 232 Jinja Road.

\par }{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 2. That on }{\rtlch\fcs1 \ab\af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 13th }{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 June 2002 a final Certificate of Settlement was concluded between the plaintiff and the defendant. The said certificate was to the effect that if the plaintiff completed the listed works in }{\rtlch\fcs1 \ab\ai\af0 \ltrch\fcs0 \b\i\insrsid16350512\charrsid726520 \'93the snag list\'94 }{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 within 10 days, the defendant would pay the plaintiff a sum of shillings }{\rtlch\fcs1 \ai\af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 32,245,4301= }{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 plus VAT (17%) after deducting 5% as retention fee and making the final figure pa}{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid726520 yable shillings 35,840,796/=. \par }{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 3. That on Saturday }{\rtlch\fcs1 \ab\af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 29th }{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 June 2002 the defendant paid the plaintiff a}{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid726520 sum of shillings 6,392,000/=. \par }{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 4. That on }{\rtlch\fcs1 \ab\af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 12th }{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 July 2002 the legal officer of the defendant communicated to the plaintiff the defendant\rquote s intention to terminate}{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid726520 the contract on l3 July 2002. \par }{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 5. That on }{\rtlch\fcs1 \ab\af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 13th }{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 July 2002 the defendant du ly terminated the contract as}{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid726520 it had indicated it would do. \par }\pard \ltrpar\s15\qj \li0\ri0\sl360\slmult1\widctlpar\wrapdefault\aspalpha\aspnum\faauto\adjustright\rin0\lin0\itap0\ipgp1\pararsid726520 {\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 The parties also agreed to admit the following documents }{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid726520 without formally proving them: \par }{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 1. A Certificate of Settlement dated }{\rtlch\fcs1 \ab\af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 13th }{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid726520 June 2002 as Exhibit P1. \par 2. A snag list as Exhibit P2. \par }{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 3. A letter from the defendant dated }{\rtlch\fcs1 \ab\af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 12th }{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 July 2002 and addressed t}{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid726520 o the plaintiff as Exhibit P3. \par }{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 4. A contract document dated l}{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid726520 9 November 2001 as Exhibit Dl. \par \par }{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 Lastly, the parties also agreed that the following would be}{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid726520 the issues for determination: \par }{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 1. Whether the defendant terminated the contract before the expiry of the agreed 10 days. }{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid726520 \par }{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 2. Whether the plaintiff}{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid726520 was in breach of the contract \par }{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 3. The}{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid726520 remedies available. \par }\pard \ltrpar\s15\qj \li0\ri0\sb100\sa240\sbauto1\sl360\slmult1\widctlpar\wrapdefault\aspalpha\aspnum\faauto\adjustright\rin0\lin0\itap0\ipgp1\pararsid726520 {\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 During the hearing of the suit the plaintiff call}{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid726520 ed two witnesses in support of }{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 its case namely, Gurbax Singh (the Managing}{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid726520 Director of the plaintiff) as }{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 PW1 and John Bakuzi (the plaintiffs supervis}{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid726520 or of the work in question) as }{ \rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 PW2. In very brief terms the }{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid726520\charrsid726520 p}{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid726520 laintiff\rquote s case was as follows: \par }{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 On 19th November 2001 the plaintiff and the defendant si gned an agreement whereby the plaintiff agreed to construct a Petrol Station for the defendant at Banda for a sum of shillings 217,231,829/=. The agreed period for the construction of the Petrol Station was 2 months. Consequently, the plaintiff was suppos e d to hand over to the defendant the completed job on 20th January 2002. The plaintiff took possession of the site on 20th November 2001 and began to do the agreed job. By 20th January 2002 the plaintiff had not yet completed the job. All the same, the pla i ntiff continued with the job until June 2002 when it thought it had completed it, but on inspection the defendant was not satisfied with it. Accordingly, on 13th June 2002 the plaintiff and the defendant signed an understanding (Exhibit P1) whereby they a greed that the plaintiff would complete the works in the snag list (Exhibit P2) in 10 days before the defendant paid it the sum of }{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid726520 shillings 3}{\rtlch\fcs1 \ai\af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 5,840,7961=. }{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 The defendant then gave the p}{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid726520 laintiff a cheque of shillings }{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 6,392,000/= dated 29th June 2002 to enable it to buy the necessary materials for the remaining works. However, since 29 June 2002 was a Saturday, the plaintiff did not bank the cheque until Monday (1st July 2002). The cheque took 3 days to mature and to credit in favour of the plaintiffs bank acc o unt. Consequently, the plaintiff did not draw the money from its bank account for buying the materials for the works in question until 4th July 2002. It then bought the necessary materials and began doing the said works. In the plaintiffs opinion if one e x cluded Sundays the plaintiff was supposed to finish the works in question on 17th July 2002. To the plaintiffs surprise on l2 July 2002 the defendant served it with a termination notice. It then proceeded to evict it from the site on 13th July 2002 when t he plaintiff was only left with cleaning and handing over the site to the defendant, thereby breaching the contract. For that reason the plaintiff implored Court to grant it the remedies it prayed for in the plaint. That was the }{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid726520\charrsid726520 plaintiff\rquote s}{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 case. }{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid726520 \par }{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 The defendant\rquote s case was slightly different. It based it on the testimony of two witnesses namely, Umo Maheswara Rao Bolle Palli (the Project engineer of the defendant) as DW1 and Caleb Mwesigwa (the defendant\rquote s legal officer) as DW2. In brief the de}{ \rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid726520 fendant\rquote s case was as follows: \par }{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 It is true the parties herein entered into the agreement referred to above. The deadline for handing over the finished job was }{\rtlch\fcs1 \ab\af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 20th}{\rtlch\fcs1 \ab\af0 \ltrch\fcs0 \b\insrsid16350512\charrsid726520 }{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 January 2002. In case of default there was a penalty clause under which the plaintiff was suppo}{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid726520 sed to pay a sum of shillings 1}{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 ,000,000/ each day it defaulted. Irrespective of the above provisions the plaintiff did not honour the deadline, but because of the penalty clause in the agreement the defendant decided to leave the matter of default until the time of fi nal payment when it would take everything into account. In May and June 2002 the plaintiff tried twice to hand over work, but the defendant found it incomplete. Finally, on 13th June 2002 the two parties entered into an understanding (Exhibit P1) whereby they agreed that the plaintiff would do the works listed in the snag list within 10 days. In turn, the defendant would pay the plaintiff the sum of money agreed upon in the understanding of }{\rtlch\fcs1 \ab\af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 13th }{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 June 2002 (Exhibit P1). On }{\rtlch\fcs1 \ab\af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 29th }{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 June 2002 the defendant advanced the plaintiff a sum of shillings }{\rtlch\fcs1 \ai\af0 \ltrch\fcs0 \insrsid726520\charrsid726520 6,329,000/}{\rtlch\fcs1 \ai\af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 =}{\rtlch\fcs1 \ai\af0 \ltrch\fcs0 \i\insrsid16350512\charrsid726520 }{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 by way of a cheque and expected it to complete the job by }{\rtlch\fcs1 \ab\af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 12th }{ \rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 July 2002. However, despite the promise it had made to complete the works in 10 days the plaintiff did not hand in the finished works on time. Instead, }{\rtlch\fcs1 \ab\af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 12th }{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 July 2002 it wrote a letter (Exhibit D2) requesting for 7 more days within which to complete the works. On receipt of the above letter the defendant terminated the contract and engaged }{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid726520\charrsid726520 someone}{ \rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 else to complete the works. For those reasons, the defendant insisted that the plaintiff breached the contract and must, among other things, pay the penalty stipulated, under the contract. Finally, the defendant prayed Court to dismiss the plaintiff\rquote s case and to grant it the remedies under the counter-claim. }{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid726520 That was the defendant\rquote s case. \par }\pard \ltrpar\s15\qj \li0\ri0\sl360\slmult1\widctlpar\wrapdefault\aspalpha\aspnum\faauto\adjustright\rin0\lin0\itap0\ipgp1\pararsid726520 {\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 After considering the evidence on record, Court thought that it was prudent to amend the issues slightly. (See }{\rtlch\fcs1 \ab\af0 \ltrch\fcs0 \b\insrsid16350512\charrsid726520 Order 13 rule }{\rtlch\fcs1 \af0 \ltrch\fcs0 \b\insrsid16350512\charrsid726520 5 }{\rtlch\fcs1 \ab\af0 \ltrch\fcs0 \b\insrsid16350512\charrsid726520 of the Civil Procedure Rules). }{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 Court was satisfied that amending the issues would not prejudi ce the interests of any of the parties involved in the dispute. Instead, it would safeguard the said interests because the amended issues would enable Court to deal with every aspect of the matter before it. Accordingly, t}{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid726520 he amended issues are follows: \par }{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 1. Whether the plaintiff breached the contract. }{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid726520 \par }{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 2. Whether the defendant was entit}{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid726520 led to terminate the contract. \par }{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 3. Whether there is merit in th}{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid726520 e defendant\rquote s counter-claim. \par 4. The available remedies. \par }\pard \ltrpar\s15\qj \li0\ri0\sb100\sa240\sbauto1\sl360\slmult1\widctlpar\wrapdefault\aspalpha\aspnum\faauto\adjustright\rin0\lin0\itap0\ipgp1\pararsid726520 {\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 Court will dispose of t}{ \rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid726520 he above issues in that order. \par }{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 With regard to the first issue }{\rtlch\fcs1 \ab\af0 \ltrch\fcs0 \b\insrsid16350512\charrsid726520 (i.e. whether the plaintiff breached the contract) }{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 both parties to the suit held different views. The plaintiff insisted that it did not breach the contract. However, the defendant disagreed. It pointed out that under the co ntract (Exhibit Dl) the plaintiff had to complete the specified job and hand it over to the defendant on 20th January 2002 but it failed to do so. Thereafter, the plaintiff continued to drag its feet until the two parties entered an understanding (Exhibit

P1) under which the plaintiff was supposed to complete the works in the snag list (Exhibit P2) in 10 days before the defendant paid it. The plaintiff failed to complete the said works within the agreed period of 10 days. Accordingly, the defendant termina ted the contract and engaged }{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid726520\charrsid726520 someon}{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid726520 e else to complete the works. \par }{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 It is not disput}{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid7866645 ed that the agreement dated l9th}{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 November 2001 is the initial one the parties entered into in respect of the job in question and that under it the plaintiff had to complete the job by 20th January 2002, but it did not. It is also not disputed that despite the plaintiff\rquote s failure to complete the job in time the defendant did not do anything about the matter until 13th June 2002 when the parties entered into an understanding (Exh ibit P1) that fixed a new deadline for the completion of the job. By its conduct, therefore, it is apparent that the defendant waived the breach of contract that occurred on }{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid726520 20th}{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 January 2002. Accordingly, it should not be heard to raise that breach against the plaintiff, for in law the defendant\rquote s conduct created an estoppel, which bars it from raising the said breach. (See section }{ \rtlch\fcs1 \ab\af0 \ltrch\fcs0 \b\insrsid16350512\charrsid726520 114 of the Evidence Act Cap. 6) }{\rtlch\fcs1 \ab\af0 \ltrch\fcs0 \b\insrsid726520 \par }{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 However, it is the events that took place after the parties signed the above understanding (E xhibit P1) dated 13th June 2002 that Court must now examine with a view to determining whether or not the plaintiff breached the contract. A perusal of the above understanding reveals that the parties did not specify when the 10 days for perfecting the wo rks in question was supposed to begin running. However, it is not}{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid726520 disputed that the cheque that }{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 was intended to facilitate the 10 days\rquote works was dated 29th June 2002, which day (according to the evidence on record) fell on a Saturday. It is also not disputed that the plaintiff could not have banked the said cheque during the weekend. For that r}{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid726520 eason it banked it on Monday (1s}{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 t July 2002). Further, there is undisputed evidence on record to the effect that the said cheque matured on 4. July 2002. Consequently , if one allowed the plaintiff a free day (i.e. 5th July 2002) for the purposes of drawing money, buying materials and delivering them on the site the plaintiff ought to have started doing the works in question on 6th July 2002. Further, if one gave the p laintiff allowance for another free day in respect of an intervening Sunday it is obvious that the plaintiff ought to have completed the works in question by 16th July 2002. However, the evidence on record shows that }{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid7866645 12}{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 th July \line 2002, under its letter Exhibi t D2, the plaintiff clearly indicated to the defendant that it would not complete the said works by 16th July 2002. For the sake of clarity, Court will reproduce the relevant parts of that lette}{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid726520 r below. They read as follows: \par }\pard \ltrpar\s15\ql \li0\ri0\sb100\sa240\sbauto1\sl360\slmult1\widctlpar\wrapdefault\aspalpha\aspnum\faauto\adjustright\rin0\lin0\itap0\ipgp1\pararsid726520 {\rtlch\fcs1 \ab\ai\af0 \ltrch\fcs0 \b\i\insrsid16350512\charrsid726520 \'93M. H. }{\rtlch\fcs1 \ab\ai\af0 \ltrch\fcs0 \b\i\ul\insrsid16350512\charrsid726520 CONSTRUCTION LIMITED }{\rtlch\fcs1 \ab\ai\af0 \ltrch\fcs0 \b\i\insrsid16350512\charrsid726520 \line July 12, 2002 \line The Legal Officer \line Petro Uganda}{\rtlch\fcs1 \ab\ai\af0 \ltrch\fcs0 \b\i\insrsid726520 Limited \par Attn: Caleb Mwesigwa \par }\pard \ltrpar\s15\qj \li0\ri0\sb100\sa240\sbauto1\sl360\slmult1\widctlpar\wrapdefault\aspalpha\aspnum\faauto\adjustright\rin0\lin0\itap0\ipgp1\pararsid726520 {\rtlch\fcs1 \ab\ai\af0 \ltrch\fcs0 \b\i\insrsid16350512\charrsid726520 RE: EXTENSION OF TIME OF OUR CONSTRUCTION CONTR}{\rtlch\fcs1 \ab\ai\af0 \ltrch\fcs0 \b\i\insrsid726520 ACT FOR BANDA PETRO STA TION: \par }{\rtlch\fcs1 \ab\ai\af0 \ltrch\fcs0 \b\i\insrsid16350512\charrsid726520 Reference is made to our letter dat}{\rtlch\fcs1 \ab\ai\af0 \ltrch\fcs0 \b\i\insrsid726520 ed July 4, 2002 specifying the }{\rtlch\fcs1 \ab\ai\af0 \ltrch\fcs0 \b\i\insrsid16350512\charrsid726520 completion}{\rtlch\fcs1 \ab\ai\af0 \ltrch\fcs0 \b\i\insrsid726520 time for Banda Petro Station. \par }{\rtlch\fcs1 \ab\ai\af0 \ltrch\fcs0 \b\i\insrsid16350512\charrsid726520 We had agreed to complete withi}{\rtlch\fcs1 \ab\ai\af0 \ltrch\fcs0 \b\i\insrsid8395441 n the (10) ten days but due to }{\rtlch\fcs1 \ab\ai\af0 \ltrch\fcs0 \b\i\insrsid16350512\charrsid726520 Disturbance of flow of traffic coming for fuel and }{\rtlch\fcs1 \ab\ai\af0 \ltrch\fcs0 \b\i\insrsid8395441 rain, we are unable to finish. \par }{\rtlch\fcs1 \ab\ai\af0 \ltrch\fcs0 \b\i\insrsid16350512\charrsid726520 We are therefore asking for more }{\rtlch\fcs1 \ab\ai\af0 \ltrch\fcs0 \b\i\insrsid8395441 one week to complete the work. \par }{\rtlch\fcs1 \ab\ai\af0 \ltrch\fcs0 \b\i\insrsid16350512\charrsid726520 Thanks for your consideration. }{\rtlch\fcs1 \ab\ai\af0 \ltrch\fcs0 \b\i\insrsid8395441 \par }\pard \ltrpar\s15\qj \li0\ri0\sl360\slmult1\widctlpar\wrapdefault\aspalpha\aspnum\faauto\adjustright\rin0\lin0\itap0\ipgp1\pararsid8395441 {\rtlch\fcs1 \ab\ai\af0 \ltrch\fcs0 \b\i\insrsid16350512\charrsid726520 Gurbax }{\rtlch\fcs1 \ab\ai\af0 \ltrch\fcs0 \b\i\insrsid8395441 Singh \par FOR: M. H. CONSTRUCTION CO. LTD \par }\pard \ltrpar\s15\ql \li0\ri0\sb100\sa240\sbauto1\sl360\slmult1\widctlpar\wrapdefault\aspalpha\aspnum\faauto\adjustright\rin0\lin0\itap0\ipgp1\pararsid8395441 {\rtlch\fcs1 \ab\ai\af0 \ltrch\fcs0 \b\i\insrsid16350512\charrsid726520 c.c. Director Petro Uganda Ltd \line c.c. The Operation manager Petro Uganda Ltd \line c.c. The Financial Manager Petro Uganda Ltd \line c.c. The Project Engineer Petro Uganda Ltd\'94 }{\rtlch\fcs1 \ab\ai\af0 \ltrch\fcs0 \b\i\insrsid8395441 \par }\pard \ltrpar\s15\qj \li0\ri0\sb100\sa240\sbauto1\sl360\slmult1\widctlpar\wrapdefault\aspalpha\aspnum\faauto\adjustright\rin0\lin0\itap0\ipgp1\pararsid726520 {\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 Form the contents of the above letter it seems that the earliest date on which the plaintiff might have possibly completed the works was now 20th July 2002, of course, once again giving allowance for another intervening Sunday of no work done. Therefore, when the defendant received the plaintiff\rquote s letter of 12th July 2002 it became evident that there was anticipatory breach. At this point in time, the defendant was at liberty to sue the plaintiff for breach of contract. }{\rtlch\fcs1 \ab\af0 \ltrch\fcs0 \b\insrsid16350512\charrsid726520 (See The Law of Contract }{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 - }{\rtlch\fcs1 \ab\af0 \ltrch\fcs0 \b\insrsid16350512\charrsid726520 Sixth Edition }{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 - }{\rtlch\fcs1 \ab\af0 \ltrch\fcs0 \b\insrsid16350512\charrsid726520 by Cheshire and Fifoot at pages 501 and }{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 502).). \line All in all, it is clear from the foregoing that the plaintiff breached the contract in question. That finding }{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid8395441 takes care of the first issue. \par }{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 With regard to the second issue }{\rtlch\fcs1 \ab\af0 \ltrch\fcs0 \b\insrsid16350512\charrsid726520 (i.e. whether the defendant was entitled to terminate the contract) }{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 again the two parties were at variance in respect of this aspect of the case. The plaintiff insisted that the defendant was not entitled to terminate the contract since the plaintiff had fully performed its part under it and merely remained with cleaning the site a nd han}{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid8395441 ding it over to the defendant. \par }{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 The defendant did not agree with the plaintiff\rquote s version abo}{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid4073394 ve. Its two witnesses Palli (DW}{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 1) and Mwesigwa (DW2) maintained that the defendant was entitled to terminate the contract because the plaintiff had committed a serious breach of the contract by failing to complete the works}{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid8395441 in the agreed period of time. \par }{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 Be that as it may, it is quite obvious that not every breach of contract entitles the innocent party to terminate the contract. It is only serious breaches tha t entitle the innocent party to terminate the contract. (See }{\rtlch\fcs1 \ab\af0 \ltrch\fcs0 \b\insrsid16350512\charrsid726520 The Law of Contract supra). }{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 The question to answer, therefore, is whether the plaintiff\rquote s breach was so serious as to entitle the defendant to terminate the contract. Court thinks that the answer to the said question is in the affirmative because the evidence on record, particularly the plaintiff\rquote s letter dated 12th July 2002 (Exhibit D2), suggests that at that point in time the plaintiff had not done much to complete the works agreed upon. Indeed , if, by 12th July 2002 the plaintiff had completed a substantial part of the works it is doubtful that it might have found it necessary to request the defendant for such a long extension (i.e. 7 days) to enable it to complete the works in question. In th e circumstances, Court is persuaded to conclude that the breach the plaintiff committed was so serious as to entitle the defend}{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid8395441 ant to terminate the contract. \par }{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 With regard to the third issue (i.e. }{\rtlch\fcs1 \ab\af0 \ltrch\fcs0 \b\insrsid16350512\charrsid726520 whether the defendant\rquote s counter-claim has merit) }{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 Court has this to say. The area of the defendant\rquote s counter-claim relating to the penalty for breach of contract has no merit and these are Court\rquote s reasons for that view. Since Court made a finding under the first issue that the defendant waived the initial breach of c ontract it is also logical to say that the said waiver affected the penalty for the breach. For the breach and the penalty go hand in glove under the contract in question. Consequently, Court has no hesitation in concluding that the defendant\rquote s stroke that waived the initial breach is the same stroke that tacitly waived th}{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid8395441 e penalty for the said breach. \par }{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 Even if the above line of argument were to be found wanting or questionable, Court would still maintain that the area of the defendant\rquote s counter-claim relat ing to the penalty has no merit because the defendant failed to justify the imposition of the said penalty. A perusal of clause 22 of the contract, which is the basis of the penalty referred to above, is quite instru}{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid8395441 ctive. It provides as follows: \par }\pard \ltrpar\s15\qj \li0\ri0\sl360\slmult1\widctlpar\wrapdefault\aspalpha\aspnum\faauto\adjustright\rin0\lin0\itap0\ipgp1\pararsid8395441 {\rtlch\fcs1 \ab\ai\af0 \ltrch\fcs0 \b\i\insrsid16350512\charrsid726520 \'93Da}{\rtlch\fcs1 \ab\ai\af0 \ltrch\fcs0 \b\i\insrsid8395441 mages for }{\rtlch\fcs1 \ab\ai\af0 \ltrch\fcs0 \b\i\insrsid16350512\charrsid726520 non-completion. }{\rtlch\fcs1 \ab\ai\af0 \ltrch\fcs0 \b\i\insrsid8395441 \par }\pard \ltrpar\s15\qj \li720\ri0\sl360\slmult1\widctlpar\wrapdefault\aspalpha\aspnum\faauto\adjustright\rin0\lin720\itap0\ipgp1\pararsid8395441 {\rtlch\fcs1 \ai\af0 \ltrch\fcs0 \b\i\insrsid16350512\charrsid8395441 22. }{\rtlch\fcs1 \ab\ai\af0 \ltrch\fcs0 \b\i\insrsid16350512\charrsid8395441 If the Contractor fails to complete the Works by the Date for Practical Completion stated in the appendix to these Conditions or within any extended time fixed under Clause 23 of these Conditions and the Architect certifies in wri ting that in his opinion the same ought reasonably so to have been completed, the Contractor shall pay or allow the Employer a sum calculated}{\rtlch\fcs1 \ab\ai\af0 \ltrch\fcs0 \b\i\insrsid16350512\charrsid726520 at the rate stated in the said appendix as liquidated and Ascertained Damages for the period during which the Work s shall so remain or have remained incomplete, and the Employer may deduct such sum from any monies due or to become due to the Contractor under the Contract\'94 }{\rtlch\fcs1 \ab\ai\af0 \ltrch\fcs0 \b\i\insrsid8395441 \par }\pard \ltrpar\s15\qj \li0\ri0\sb100\sa240\sbauto1\sl360\slmult1\widctlpar\wrapdefault\aspalpha\aspnum\faauto\adjustright\rin0\lin0\itap0\ipgp1\pararsid726520 {\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 It appears from the foregoing that before a penalty could be imposed upon a Contractor for non-completion of a job within a specified period of time under the contract, there must be certification by }{\rtlch\fcs1 \ab\ai\af0 \ltrch\fcs0 \b\i\insrsid16350512\charrsid726520 \'93the Architect\'94 }{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 in writing to the effect that the work lying uncompleted }{\rtlch\fcs1 \ab\ai\af0 \ltrch\fcs0 \b\i\insrsid16350512\charrsid726520 \'93 ought reasonably...to have been completed\'94 }{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 in the time agreed upon. Needless t o say, in the instant case, the defendant did not produce such certification and there is none to that effect on record. For that reason, it seems that legally no penalty could be imposed under clause 22 of the contract in the circumstances of the case th at is}{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid8395441 the subject of this judgment. \par }{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 In short, the defendant failed to prove that it is entitled to impose the penalty referred to in clause 22 of the contract. Therefore, as earlier on pointed out the part of the defendant \rquote s counter-claim relating to the penalty for br}{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid8395441 each of contract has no merit. \par }{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 As far as the part of the defendant\rquote s counter-claim relating to general damages is concerned Court has this to say. Since Court made a finding earlier on that the plaintiff breached the understanding }{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid8395441 of }{\rtlch\fcs1 \ab\af0 \ltrch\fcs0 \insrsid16350512\charrsid8395441 13th}{\rtlch\fcs1 \ab\af0 \ltrch\fcs0 \b\insrsid16350512\charrsid726520 }{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 June 2002, it follows that the defendant\rquote s claim for general damages in respect of that}{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid8395441 breach of contract has merit. \par }{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 All in all, the above findings wholly}{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid8395441 take care of the third issue. \par }{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 With regard to the fourth issue }{\rtlch\fcs1 \ab\af0 \ltrch\fcs0 \b\insrsid16350512\charrsid726520 (i.e. the available remedies) }{\rtlch\fcs1 \ab\af0 \ltrch\fcs0 \insrsid16350512\charrsid8395441 Court }{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 has this to say. The sum total of the foregoing is that the plaintiff\rquote s suit has failed and Court must dismiss it with costs, but the defendant \rquote s counter-claim has succeeded in the area of general damages. Therefore, Court \line must give the defendant an}{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid8395441 award in respect thereof. \par }{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 According to Mwesigwa (DW2), as a result of the plaintiffs failure to complete the agreed works in time the defendant suffered inconvenience in that he had to engage some other persons to complete the said works. For that reason, the def endant insisted that it was entitled to an award of general damages for the inconvenience it suffered on accou}{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid8395441 nt of the plaintiff\rquote s breach of contract. \par }{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 The plaintiff did not, in any way, contradict the defendant\rquote s evidence }{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid8395441 referred to above. }{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 Therefore, Court must find that the defendant suffered inconvenience as a result of the }{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid8395441\charrsid726520 plaintiff\rquote s}{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 failure to complete the works specified under the snag list (Exhibit P2) in the agreed time of 10 days. Therefore, taking into account all, Court thinks that a sum of sh illings 5,000,000/= is adequate to compensate the defendant for the inconvenience it suffered as a result of the plaintiffs breach of contract. The above sum of money will attract interest at Court rate from today until the plaintiff fully pays}{ \rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid8395441 it. \par }{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 In conclusion, Court m}{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid8395441 ust make the following orders: \par }{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 1. Court hereby dismisses the plaintiffs suit with costs and enters judgment in favour of the defendant on the counter-claim for the sum of shillings 5}{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid8395441 ,000,000/= as general damages. \par }{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 2. The plaintiff will pay the defendant interest on the sum of money referred to in paragraph 2 above at Court rate fro}{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid8395441 m today until payment in full. \par }{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 3. The plaintiff will also bear t}{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid8395441 he costs of the counter-claim. \par }\pard \ltrpar\s15\qc \li0\ri0\sl360\slmult1\widctlpar\wrapdefault\aspalpha\aspnum\faauto\adjustright\rin0\lin0\itap0\ipgp1\pararsid6384804 {\rtlch\fcs1 \ab\af0 \ltrch\fcs0 \insrsid6384804\charrsid8395441 E. S. Lugayizi \par }{\rtlch\fcs1 \ab\af0 \ltrch\fcs0 \b\insrsid6384804\charrsid726520 (JUDGE) \line }{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid6384804\charrsid726520 14/2/2005 \par }\pard \ltrpar\s15\qj \li0\ri0\sl360\slmult1\widctlpar\wrapdefault\aspalpha\aspnum\faauto\adjustright\rin0\lin0\itap0\ipgp1\pararsid8395441 {\rtlch\fcs1 \ab\af0 \ltrch\fcs0 \b\insrsid16350512\charrsid726520 Read before: At }{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid8395441 9. 38 a.m. \par }\pard \ltrpar\s15\ql \li0\ri0\sl360\slmult1\widctlpar\wrapdefault\aspalpha\aspnum\faauto\adjustright\rin0\lin0\itap0\ipgp1\pararsid8395441 {\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 The }{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid8395441\charrsid726520 plaintiff\rquote s}{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 rep. \line The defendant\rquote s rep. \line Mr. Nyombi for the plaintiff \line Mr. Kandebe for the defendant \line Mr. Sewanyana c/clerk

\par }\pard \ltrpar\s15\qc \li0\ri0\sl360\slmult1\widctlpar\wrapdefault\aspalpha\aspnum\faauto\adjustright\rin0\lin0\itap0\pararsid8395441 {\rtlch\fcs1 \ab\af0 \ltrch\fcs0 \insrsid8395441\charrsid8395441 E. S. Lugayizi \par }{\rtlch\fcs1 \ab\af0 \ltrch\fcs0 \b\insrsid8395441\charrsid726520 (JUDGE) \line }{\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid8395441\charrsid726520 14/2/2005 \par }\pard\plain \ltrpar\qj \li0\ri0\sl360\slmult1\widctlpar\wrapdefault\aspalpha\aspnum\faauto\adjustright\rin0\lin0\itap0\pararsid726520 \rtlch\fcs1 \af0\afs24\alang1025 \ltrch\fcs0 \fs24\lang1033\langfe1033\cgrid\langnp1033\langfenp1033 {\rtlch\fcs1 \af0 \ltrch\fcs0 \insrsid16350512\charrsid726520 \par }{\*\themedata 504b030414000600080000002100828abc13fa0000001c020000130000005b436f6e74656e745f54797065735d2e786d6cac91cb6ac3301045f785fe83d0b6d8 72ba28a5d8cea249777d2cd20f18e4b12d6a8f843409c9df77ecb850ba082d74231062ce997b55ae8fe3a00e1893f354e9555e6885647de3a8abf4fbee29bbd7 2a3150038327acf409935ed7d757e5ee14302999a654e99e393c18936c8f23a4dc072479697d1c81e51a3b13c07e4087e6b628ee8cf5c4489cf1c4d075f92a0b 44d7a07a83c82f308ac7b0a0f0fbf90c2480980b58abc733615aa2d210c2e02cb04430076a7ee833dfb6ce62e3ed7e14693e8317d8cd0433bf5c60f53fea2fe7 065bd80facb647e9e25c7fc421fd2ddb526b2e9373fed4bb902e182e97b7b461e6bfad3f010000ffff0300504b030414000600080000002100a5d6a7e7c00000 00360100000b0000005f72656c732f2e72656c73848fcf6ac3300c87ef85bd83d17d51d2c31825762fa590432fa37d00e1287f68221bdb1bebdb4fc7060abb08 84a4eff7a93dfeae8bf9e194e720169aaa06c3e2433fcb68e1763dbf7f82c985a4a725085b787086a37bdbb55fbc50d1a33ccd311ba548b63095120f88d94fbc 52ae4264d1c910d24a45db3462247fa791715fd71f989e19e0364cd3f51652d73760ae8fa8c9ffb3c330cc9e4fc17faf2ce545046e37944c69e462a1a82fe353 bd90a865aad41ed0b5b8f9d6fd010000ffff0300504b0304140006000800000021006b799616830000008a0000001c0000007468656d652f7468656d652f7468 656d654d616e616765722e786d6c0ccc4d0ac3201040e17da17790d93763bb284562b2cbaebbf600439c1a41c7a0d29fdbd7e5e38337cedf14d59b4b0d592c9c 070d8a65cd2e88b7f07c2ca71ba8da481cc52c6ce1c715e6e97818c9b48d13df49c873517d23d59085adb5dd20d6b52bd521ef2cdd5eb9246a3d8b4757e8d3f7 29e245eb2b260a0238fd010000ffff0300504b03041400060008000000210096b5ade296060000501b0000160000007468656d652f7468656d652f7468656d65 312e786d6cec594f6fdb3614bf0fd87720746f6327761a07758ad8b19b2d4d1bc46e871e698996d850a240d2497d1bdae38001c3ba618715d86d87615b8116d8 a5fb34d93a6c1dd0afb0475292c5585e9236d88aad3e2412f9e3fbff1e1fa9abd7eec70c1d1221294fda5efd72cd4324f1794093b0eddd1ef62fad79482a9c04 98f184b4bd2991deb58df7dfbb8ad755446282607d22d771db8b944ad79796a40fc3585ee62949606ecc458c15bc8a702910f808e8c66c69b9565b5d8a314d3c 94e018c8de1a8fa94fd05093f43672e23d06af89927ac06762a049136785c10607758d9053d965021d62d6f6804fc08f86e4bef210c352c144dbab999fb7b471 7509af678b985ab0b6b4ae6f7ed9ba6c4170b06c788a705430adf71bad2b5b057d03606a1ed7ebf5babd7a41cf00b0ef83a6569632cd467faddec9699640f671 9e76b7d6ac355c7c89feca9cccad4ea7d36c65b258a206641f1b73f8b5da6a6373d9c11b90c537e7f08dce66b7bbeae00dc8e257e7f0fd2badd5868b37a088d1 e4600ead1ddaef67d40bc898b3ed4af81ac0d76a197c86826828a24bb318f3442d8ab518dfe3a20f000d6458d104a9694ac6d88728eee2782428d60cf03ac1a5 193be4cbb921cd0b495fd054b5bd0f530c1931a3f7eaf9f7af9e3f45c70f9e1d3ff8e9f8e1c3e3073f5a42ceaa6d9c84e5552fbffdeccfc71fa33f9e7ef3f2d1 17d57859c6fffac327bffcfc793510d26726ce8b2f9ffcf6ecc98baf3efdfdbb4715f04d814765f890c644a29be408edf3181433567125272371be15c308d3f2 8acd249438c19a4b05fd9e8a1cf4cd296699771c393ac4b5e01d01e5a30a787d72cf1178108989a2159c77a2d801ee72ce3a5c545a6147f32a99793849c26ae6 6252c6ed637c58c5bb8b13c7bfbd490a75330f4b47f16e441c31f7184e140e494214d273fc80900aedee52ead87597fa824b3e56e82e451d4c2b4d32a423279a 668bb6690c7e9956e90cfe766cb37b077538abd27a8b1cba48c80acc2a841f12e698f13a9e281c57911ce298950d7e03aba84ac8c154f8655c4f2af074481847 bd804859b5e696007d4b4edfc150b12addbecba6b18b148a1e54d1bc81392f23b7f84137c2715a851dd0242a633f900710a218ed715505dfe56e86e877f0034e 16bafb0e258ebb4faf06b769e888340b103d3311da9750aa9d0a1cd3e4efca31a3508f6d0c5c5c398602f8e2ebc71591f5b616e24dd893aa3261fb44f95d843b 5974bb5c04f4edafb95b7892ec1108f3f98de75dc97d5772bdff7cc95d94cf672db4b3da0a6557f70db629362d72bcb0431e53c6066acac80d699a6409fb44d0 8741bdce9c0e4971624a2378cceaba830b05366b90e0ea23aaa241845368b0eb9e2612ca8c742851ca251ceccc70256d8d87265dd96361531f186c3d9058edf2 c00eafe8e1fc5c509031bb4d680e9f39a3154de0accc56ae644441edd76156d7429d995bdd88664a9dc3ad50197c38af1a0c16d684060441db02565e85f3b966 0d0713cc48a0ed6ef7dedc2dc60b17e92219e180643ed27acffba86e9c94c78ab90980d8a9f0913ee49d62b512b79626fb06dccee2a432bbc60276b9f7dec44b 7904cfbca4f3f6443ab2a49c9c2c41476dafd55c6e7ac8c769db1bc399161ee314bc2e75cf8759081743be1236ec4f4d6693e5336fb672c5dc24a8c33585b5fb 9cc24e1d4885545b58463634cc5416022cd19cacfccb4d30eb45296023fd35a458598360f8d7a4003bbaae25e331f155d9d9a5116d3bfb9a95523e51440ca2e0 088dd844ec6370bf0e55d027a012ae264c45d02f708fa6ad6da6dce29c255df9f6cae0ec38666984b372ab5334cf640b37795cc860de4ae2816e95b21be5ceaf 8a49f90b52a51cc6ff3355f47e0237052b81f6800fd7b802239daf6d8f0b1571a8426944fdbe80c6c1d40e8816b88b8569082ab84c36ff0539d4ff6dce591a26 ade1c0a7f669880485fd484582903d284b26fa4e2156cff62e4b9265844c4495c495a9157b440e091bea1ab8aaf7760f4510eaa69a6465c0e04ec69ffb9e65d0 28d44d4e39df9c1a52ecbd3607fee9cec7263328e5d661d3d0e4f62f44acd855ed7ab33cdf7bcb8ae889599bd5c8b3029895b6825696f6af29c239b75a5bb1e6 345e6ee6c28117e73586c1a2214ae1be07e93fb0ff51e133fb65426fa843be0fb515c187064d0cc206a2fa926d3c902e907670048d931db4c1a44959d366ad93 b65abe595f70a75bf03d616c2dd959fc7d4e6317cd99cbcec9c58b34766661c7d6766ca1a9c1b327531486c6f941c638c67cd22a7f75e2a37be0e82db8df9f30 254d30c1372581a1f51c983c80e4b71ccdd28dbf000000ffff0300504b0304140006000800000021000dd1909fb60000001b010000270000007468656d652f74 68656d652f5f72656c732f7468656d654d616e616765722e786d6c2e72656c73848f4d0ac2301484f78277086f6fd3ba109126dd88d0add40384e4350d363f24 51eced0dae2c082e8761be9969bb979dc9136332de3168aa1a083ae995719ac16db8ec8e4052164e89d93b64b060828e6f37ed1567914b284d262452282e3198 720e274a939cd08a54f980ae38a38f56e422a3a641c8bbd048f7757da0f19b017cc524bd62107bd5001996509affb3fd381a89672f1f165dfe514173d9850528 a2c6cce0239baa4c04ca5bbabac4df000000ffff0300504b01022d0014000600080000002100828abc13fa0000001c0200001300000000000000000000000000 000000005b436f6e74656e745f54797065735d2e786d6c504b01022d0014000600080000002100a5d6a7e7c0000000360100000b000000000000000000000000 002b0100005f72656c732f2e72656c73504b01022d00140006000800000021006b799616830000008a0000001c00000000000000000000000000140200007468 656d652f7468656d652f7468656d654d616e616765722e786d6c504b01022d001400060008000000210096b5ade296060000501b000016000000000000000000 00000000d10200007468656d652f7468656d652f7468656d65312e786d6c504b01022d00140006000800000021000dd1909fb60000001b010000270000000000 00000000000000009b0900007468656d652f7468656d652f5f72656c732f7468656d654d616e616765722e786d6c2e72656c73504b050600000000050005005d010000960a00000000} {\*\colorschememapping 3c3f786d6c2076657273696f6e3d22312e302220656e636f64696e673d225554462d3822207374616e64616c6f6e653d22796573223f3e0d0a3c613a636c724d 617020786d6c6e733a613d22687474703a2f2f736368656d61732e6f70656e786d6c666f726d6174732e6f72672f64726177696e676d6c2f323030362f6d6169 6e22206267313d226c743122207478313d22646b3122206267323d226c743222207478323d22646b322220616363656e74313d22616363656e74312220616363 656e74323d22616363656e74322220616363656e74333d22616363656e74332220616363656e74343d22616363656e74342220616363656e74353d22616363656e74352220616363656e74363d22616363656e74362220686c696e6b3d22686c696e6b2220666f6c486c696e6b3d22666f6c486c696e6b222f3e} {\*\latentstyles\lsdstimax267\lsdlockeddef0\lsdsemihiddendef1\lsdunhideuseddef1\lsdqformatdef0\lsdprioritydef99{\lsdlockedexcept \lsdsemihidden0 \lsdunhideused0 \lsdqformat1 \lsdpriority0 \lsdlocked0 Normal; \lsdsemihidden0 \lsdunhideused0 \lsdqformat1 \lsdpriority9 \lsdlocked0 heading 1;\lsdqformat1 \lsdpriority9 \lsdlocked0 heading 2;\lsdqformat1 \lsdpriority9 \lsdlocked0 heading 3;\lsdqformat1 \lsdpriority9 \lsdlocked0 heading 4; \lsdqformat1 \lsdpriority9 \lsdlocked0 heading 5;\lsdqformat1 \lsdpriority9 \lsdlocked0 heading 6;\lsdqformat1 \lsdpriority9 \lsdlocked0 heading 7;\lsdqformat1 \lsdpriority9 \lsdlocked0 heading 8;\lsdqformat1 \lsdpriority9 \lsdlocked0 heading 9; \lsdpriority39 \lsdlocked0 toc 1;\lsdpriority39 \lsdlocked0 toc 2;\lsdpriority39 \lsdlocked0 toc 3;\lsdpriority39 \lsdlocked0 toc 4;\lsdpriority39 \lsdlocked0 toc 5;\lsdpriority39 \lsdlocked0 toc 6;\lsdpriority39 \lsdlocked0 toc 7; \lsdpriority39 \lsdlocked0 toc 8;\lsdpriority39 \lsdlocked0 toc 9;\lsdqformat1 \lsdpriority35 \lsdlocked0 caption;\lsdsemihidden0 \lsdunhideused0 \lsdqformat1 \lsdpriority10 \lsdlocked0 Title;\lsdpriority1 \lsdlocked0 Default Paragraph Font; \lsdsemihidden0 \lsdunhideused0 \lsdqformat1 \lsdpriority11 \lsdlocked0 Subtitle;\lsdsemihidden0 \lsdunhideused0 \lsdqformat1 \lsdpriority22 \lsdlocked0 Strong;\lsdsemihidden0 \lsdunhideused0 \lsdqformat1 \lsdpriority20 \lsdlocked0 Emphasis; \lsdsemihidden0 \lsdunhideused0 \lsdpriority59 \lsdlocked0 Table Grid;\lsdunhideused0 \lsdlocked0 Placeholder Text;\lsdsemihidden0 \lsdunhideused0 \lsdqformat1 \lsdpriority1 \lsdlocked0 No Spacing; \lsdsemihidden0 \lsdunhideused0 \lsdpriority60 \lsdlocked0 Light Shading;\lsdsemihidden0 \lsdunhideused0 \lsdpriority61 \lsdlocked0 Light List;\lsdsemihidden0 \lsdunhideused0 \lsdpriority62 \lsdlocked0 Light Grid; \lsdsemihidden0 \lsdunhideused0 \lsdpriority63 \lsdlocked0 Medium Shading 1;\lsdsemihidden0 \lsdunhideused0 \lsdpriority64 \lsdlocked0 Medium Shading 2;\lsdsemihidden0 \lsdunhideused0 \lsdpriority65 \lsdlocked0 Medium List 1; \lsdsemihidden0 \lsdunhideused0 \lsdpriority66 \lsdlocked0 Medium List 2;\lsdsemihidden0 \lsdunhideused0 \lsdpriority67 \lsdlocked0 Medium Grid 1;\lsdsemihidden0 \lsdunhideused0 \lsdpriority68 \lsdlocked0 Medium Grid 2; \lsdsemihidden0 \lsdunhideused0 \lsdpriority69 \lsdlocked0 Medium Grid 3;\lsdsemihidden0 \lsdunhideused0 \lsdpriority70 \lsdlocked0 Dark List;\lsdsemihidden0 \lsdunhideused0 \lsdpriority71 \lsdlocked0 Colorful Shading; \lsdsemihidden0 \lsdunhideused0 \lsdpriority72 \lsdlocked0 Colorful List;\lsdsemihidden0 \lsdunhideused0 \lsdpriority73 \lsdlocked0 Colorful Grid;\lsdsemihidden0 \lsdunhideused0 \lsdpriority60 \lsdlocked0 Light Shading Accent 1; \lsdsemihidden0 \lsdunhideused0 \lsdpriority61 \lsdlocked0 Light List Accent 1;\lsdsemihidden0 \lsdunhideused0 \lsdpriority62 \lsdlocked0 Light Grid Accent 1;\lsdsemihidden0 \lsdunhideused0 \lsdpriority63 \lsdlocked0 Medium Shading 1 Accent 1; \lsdsemihidden0 \lsdunhideused0 \lsdpriority64 \lsdlocked0 Medium Shading 2 Accent 1;\lsdsemihidden0 \lsdunhideused0 \lsdpriority65 \lsdlocked0 Medium List 1 Accent 1;\lsdunhideused0 \lsdlocked0 Revision; \lsdsemihidden0 \lsdunhideused0 \lsdqformat1 \lsdpriority34 \lsdlocked0 List Paragraph;\lsdsemihidden0 \lsdunhideused0 \lsdqformat1 \lsdpriority29 \lsdlocked0 Quote;\lsdsemihidden0 \lsdunhideused0 \lsdqformat1 \lsdpriority30 \lsdlocked0 Intense Quote; \lsdsemihidden0 \lsdunhideused0 \lsdpriority66 \lsdlocked0 Medium List 2 Accent 1;\lsdsemihidden0 \lsdunhideused0 \lsdpriority67 \lsdlocked0 Medium Grid 1 Accent 1;\lsdsemihidden0 \lsdunhideused0 \lsdpriority68 \lsdlocked0 Medium Grid 2 Accent 1; \lsdsemihidden0 \lsdunhideused0 \lsdpriority69 \lsdlocked0 Medium Grid 3 Accent 1;\lsdsemihidden0 \lsdunhideused0 \lsdpriority70 \lsdlocked0 Dark List Accent 1;\lsdsemihidden0 \lsdunhideused0 \lsdpriority71 \lsdlocked0 Colorful Shading Accent 1; \lsdsemihidden0 \lsdunhideused0 \lsdpriority72 \lsdlocked0 Colorful List Accent 1;\lsdsemihidden0 \lsdunhideused0 \lsdpriority73 \lsdlocked0 Colorful Grid Accent 1;\lsdsemihidden0 \lsdunhideused0 \lsdpriority60 \lsdlocked0 Light Shading Accent 2; \lsdsemihidden0 \lsdunhideused0 \lsdpriority61 \lsdlocked0 Light List Accent 2;\lsdsemihidden0 \lsdunhideused0 \lsdpriority62 \lsdlocked0 Light Grid Accent 2;\lsdsemihidden0 \lsdunhideused0 \lsdpriority63 \lsdlocked0 Medium Shading 1 Accent 2; \lsdsemihidden0 \lsdunhideused0 \lsdpriority64 \lsdlocked0 Medium Shading 2 Accent 2;\lsdsemihidden0 \lsdunhideused0 \lsdpriority65 \lsdlocked0 Medium List 1 Accent 2;\lsdsemihidden0 \lsdunhideused0 \lsdpriority66 \lsdlocked0 Medium List 2 Accent 2; \lsdsemihidden0 \lsdunhideused0 \lsdpriority67 \lsdlocked0 Medium Grid 1 Accent 2;\lsdsemihidden0 \lsdunhideused0 \lsdpriority68 \lsdlocked0 Medium Grid 2 Accent 2;\lsdsemihidden0 \lsdunhideused0 \lsdpriority69 \lsdlocked0 Medium Grid 3 Accent 2; \lsdsemihidden0 \lsdunhideused0 \lsdpriority70 \lsdlocked0 Dark List Accent 2;\lsdsemihidden0 \lsdunhideused0 \lsdpriority71 \lsdlocked0 Colorful Shading Accent 2;\lsdsemihidden0 \lsdunhideused0 \lsdpriority72 \lsdlocked0 Colorful List Accent 2; \lsdsemihidden0 \lsdunhideused0 \lsdpriority73 \lsdlocked0 Colorful Grid Accent 2;\lsdsemihidden0 \lsdunhideused0 \lsdpriority60 \lsdlocked0 Light Shading Accent 3;\lsdsemihidden0 \lsdunhideused0 \lsdpriority61 \lsdlocked0 Light List Accent 3; \lsdsemihidden0 \lsdunhideused0 \lsdpriority62 \lsdlocked0 Light Grid Accent 3;\lsdsemihidden0 \lsdunhideused0 \lsdpriority63 \lsdlocked0 Medium Shading 1 Accent 3;\lsdsemihidden0 \lsdunhideused0 \lsdpriority64 \lsdlocked0 Medium Shading 2 Accent 3; \lsdsemihidden0 \lsdunhideused0 \lsdpriority65 \lsdlocked0 Medium List 1 Accent 3;\lsdsemihidden0 \lsdunhideused0 \lsdpriority66 \lsdlocked0 Medium List 2 Accent 3;\lsdsemihidden0 \lsdunhideused0 \lsdpriority67 \lsdlocked0 Medium Grid 1 Accent 3; \lsdsemihidden0 \lsdunhideused0 \lsdpriority68 \lsdlocked0 Medium Grid 2 Accent 3;\lsdsemihidden0 \lsdunhideused0 \lsdpriority69 \lsdlocked0 Medium Grid 3 Accent 3;\lsdsemihidden0 \lsdunhideused0 \lsdpriority70 \lsdlocked0 Dark List Accent 3; \lsdsemihidden0 \lsdunhideused0 \lsdpriority71 \lsdlocked0 Colorful Shading Accent 3;\lsdsemihidden0 \lsdunhideused0 \lsdpriority72 \lsdlocked0 Colorful List Accent 3;\lsdsemihidden0 \lsdunhideused0 \lsdpriority73 \lsdlocked0 Colorful Grid Accent 3; \lsdsemihidden0 \lsdunhideused0 \lsdpriority60 \lsdlocked0 Light Shading Accent 4;\lsdsemihidden0 \lsdunhideused0 \lsdpriority61 \lsdlocked0 Light List Accent 4;\lsdsemihidden0 \lsdunhideused0 \lsdpriority62 \lsdlocked0 Light Grid Accent 4; \lsdsemihidden0 \lsdunhideused0 \lsdpriority63 \lsdlocked0 Medium Shading 1 Accent 4;\lsdsemihidden0 \lsdunhideused0 \lsdpriority64 \lsdlocked0 Medium Shading 2 Accent 4;\lsdsemihidden0 \lsdunhideused0 \lsdpriority65 \lsdlocked0 Medium List 1 Accent 4; \lsdsemihidden0 \lsdunhideused0 \lsdpriority66 \lsdlocked0 Medium List 2 Accent 4;\lsdsemihidden0 \lsdunhideused0 \lsdpriority67 \lsdlocked0 Medium Grid 1 Accent 4;\lsdsemihidden0 \lsdunhideused0 \lsdpriority68 \lsdlocked0 Medium Grid 2 Accent 4; \lsdsemihidden0 \lsdunhideused0 \lsdpriority69 \lsdlocked0 Medium Grid 3 Accent 4;\lsdsemihidden0 \lsdunhideused0 \lsdpriority70 \lsdlocked0 Dark List Accent 4;\lsdsemihidden0 \lsdunhideused0 \lsdpriority71 \lsdlocked0 Colorful Shading Accent 4; \lsdsemihidden0 \lsdunhideused0 \lsdpriority72 \lsdlocked0 Colorful List Accent 4;\lsdsemihidden0 \lsdunhideused0 \lsdpriority73 \lsdlocked0 Colorful Grid Accent 4;\lsdsemihidden0 \lsdunhideused0 \lsdpriority60 \lsdlocked0 Light Shading Accent 5; \lsdsemihidden0 \lsdunhideused0 \lsdpriority61 \lsdlocked0 Light List Accent 5;\lsdsemihidden0 \lsdunhideused0 \lsdpriority62 \lsdlocked0 Light Grid Accent 5;\lsdsemihidden0 \lsdunhideused0 \lsdpriority63 \lsdlocked0 Medium Shading 1 Accent 5; \lsdsemihidden0 \lsdunhideused0 \lsdpriority64 \lsdlocked0 Medium Shading 2 Accent 5;\lsdsemihidden0 \lsdunhideused0 \lsdpriority65 \lsdlocked0 Medium List 1 Accent 5;\lsdsemihidden0 \lsdunhideused0 \lsdpriority66 \lsdlocked0 Medium List 2 Accent 5; \lsdsemihidden0 \lsdunhideused0 \lsdpriority67 \lsdlocked0 Medium Grid 1 Accent 5;\lsdsemihidden0 \lsdunhideused0 \lsdpriority68 \lsdlocked0 Medium Grid 2 Accent 5;\lsdsemihidden0 \lsdunhideused0 \lsdpriority69 \lsdlocked0 Medium Grid 3 Accent 5; \lsdsemihidden0 \lsdunhideused0 \lsdpriority70 \lsdlocked0 Dark List Accent 5;\lsdsemihidden0 \lsdunhideused0 \lsdpriority71 \lsdlocked0 Colorful Shading Accent 5;\lsdsemihidden0 \lsdunhideused0 \lsdpriority72 \lsdlocked0 Colorful List Accent 5; \lsdsemihidden0 \lsdunhideused0 \lsdpriority73 \lsdlocked0 Colorful Grid Accent 5;\lsdsemihidden0 \lsdunhideused0 \lsdpriority60 \lsdlocked0 Light Shading Accent 6;\lsdsemihidden0 \lsdunhideused0 \lsdpriority61 \lsdlocked0 Light List Accent 6; \lsdsemihidden0 \lsdunhideused0 \lsdpriority62 \lsdlocked0 Light Grid Accent 6;\lsdsemihidden0 \lsdunhideused0 \lsdpriority63 \lsdlocked0 Medium Shading 1 Accent 6;\lsdsemihidden0 \lsdunhideused0 \lsdpriority64 \lsdlocked0 Medium Shading 2 Accent 6; \lsdsemihidden0 \lsdunhideused0 \lsdpriority65 \lsdlocked0 Medium List 1 Accent 6;\lsdsemihidden0 \lsdunhideused0 \lsdpriority66 \lsdlocked0 Medium List 2 Accent 6;\lsdsemihidden0 \lsdunhideused0 \lsdpriority67 \lsdlocked0 Medium Grid 1 Accent 6; \lsdsemihidden0 \lsdunhideused0 \lsdpriority68 \lsdlocked0 Medium Grid 2 Accent 6;\lsdsemihidden0 \lsdunhideused0 \lsdpriority69 \lsdlocked0 Medium Grid 3 Accent 6;\lsdsemihidden0 \lsdunhideused0 \lsdpriority70 \lsdlocked0 Dark List Accent 6; \lsdsemihidden0 \lsdunhideused0 \lsdpriority71 \lsdlocked0 Colorful Shading Accent 6;\lsdsemihidden0 \lsdunhideused0 \lsdpriority72 \lsdlocked0 Colorful List Accent 6;\lsdsemihidden0 \lsdunhideused0 \lsdpriority73 \lsdlocked0 Colorful Grid Accent 6; \lsdsemihidden0 \lsdunhideused0 \lsdqformat1 \lsdpriority19 \lsdlocked0 Subtle Emphasis;\lsdsemihidden0 \lsdunhideused0 \lsdqformat1 \lsdpriority21 \lsdlocked0 Intense Emphasis; \lsdsemihidden0 \lsdunhideused0 \lsdqformat1 \lsdpriority31 \lsdlocked0 Subtle Reference;\lsdsemihidden0 \lsdunhideused0 \lsdqformat1 \lsdpriority32 \lsdlocked0 Intense Reference; \lsdsemihidden0 \lsdunhideused0 \lsdqformat1 \lsdpriority33 \lsdlocked0 Book Title;\lsdpriority37 \lsdlocked0 Bibliography;\lsdqformat1 \lsdpriority39 \lsdlocked0 TOC Heading;}}{\*\datastore 010500000200000018000000 4d73786d6c322e534158584d4c5265616465722e352e3000000000000000000000060000 d0cf11e0a1b11ae1000000000000000000000000000000003e000300feff090006000000000000000000000001000000010000000000000000100000feffffff00000000feffffff0000000000000000ffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffff ffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffff ffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffff ffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffff fffffffffffffffffdfffffffeffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffff ffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffff ffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffff ffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffffff ffffffffffffffffffffffffffffffff52006f006f007400200045006e00740072007900000000000000000000000000000000000000000000000000000000000000000000000000000000000000000016000500ffffffffffffffffffffffffec69d9888b8b3d4c859eaf6cd158be0f00000000000000000000000070f1 f926cb03cb01feffffff00000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000ffffffffffffffffffffffff00000000000000000000000000000000000000000000000000000000 00000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000ffffffffffffffffffffffff0000000000000000000000000000000000000000000000000000 000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000ffffffffffffffffffffffff000000000000000000000000000000000000000000000000 0000000000000000000000000000000000000000000000000105000000000000}}