Loi du 7 septembre 1987 autorisant le Gouvernement à procéder à l'extension du troisième bâtiment administratif pour le parlement européen à Luxembourg-Kirchberg.

This preamble introduces a Luxembourg law authorizing the Government to extend the third administrative building for the European Parliament in Luxembourg-Kirchberg.

AI-assisted research synopsis — verify against the official legal text below.

Jurisdiction: Luxembourg
Instrument: Act or statute
Citation: http://data.legilux.public.lu/eli/etat/leg/loi/1987/09/07/n7/jo
Status: In force
Version: Undated source snapshot
Language: fr
Updated: 7 Sept 1987
Official source: View official record ↗

budget control construction government authorization project spending limits

Publicly available, excluded from search-engine indexing

This page remains available for direct access and API use, but this release emits noindex,follow for the following reason:

The record does not meet this release's canonical indexing criteria. (market-indexing-disabled)

Statute overview

About this statute

This preamble introduces a Luxembourg law authorizing the Government to extend the third administrative building for the European Parliament in Luxembourg-Kirchberg. The Government is authorized to arrange the extension of the third administrative building for the European Parliament in Luxembourg-Kirchberg. Spending on the works in the preceding article must not exceed 850 million francs, subject to legal price increases until completion of the works.

Read the provisions Ask with citations

Search within this statute

Search all stored provisions in this version.

Legal text

Provisions of Loi du 7 septembre 1987 autorisant le Gouvernement à procéder à l'extension du troisième bâtiment administratif pour le parlement européen à Luxembourg-Kirchberg.

Showing 3 of 3

Part preamble

Preamble

preamble
Preamble
Verify source ↗

AI-assisted research summary: This preamble introduces a Luxembourg law authorizing the Government to extend the third administrative building for the European Parliament in Luxembourg-Kirchberg.

Le contenu de la version HTML du Journal officiel luxembourgeois est identique Ã la version PDF. Loi du 7 septembre 1987 autorisant le Gouvernement Ã procÃ©der Ã l'extension du troisiÃ¨me bÃ¢timent administratif pour le parlement europÃ©en Ã Luxembourg-Kirchberg. Nous JEAN, par la grÃ¢ce de Dieu, Grand-Duc de Luxembourg, Duc de Nassau; Notre Conseil d'Etat entendu; De l'assentiment de la Chambre des DÃ©putÃ©s; Vu la dÃ©cision de la Chambre des DÃ©putÃ©s du 18 juin 1987 et celle du Conseil d'Etat du 25 juin 1987 portant qu'il n'y a pas lieu Ã second vote; Avons ordonnÃ© et ordonnons: â

1 er
Art. 1 er .
Verify source ↗

AI-assisted research summary: The Government is authorized to arrange the extension of the third administrative building for the European Parliament in Luxembourg-Kirchberg.

Art. 1 er . Le Gouvernement est autorisÃ© Ã faire procÃ©der Ã l'extension du troisiÃ¨me bÃ¢timent administratif pour le parlement europÃ©en Ã Luxembourg-Kirchberg. â
2
Art. 2.
Verify source ↗

AI-assisted research summary: Spending on the works in the preceding article must not exceed 850 million francs, subject to legal price increases until completion of the works.

Art. 2. Les dÃ©penses occasionnÃ©es par l'exÃ©cution des travaux visÃ©s Ã l'article qui prÃ©cÃ¨de ne peuvent dÃ©passer la somme de huit cent cinquante millions de francs, sans prÃ©judice de l'incidence des hausses lÃ©gales de prix pouvant intervenir jusqu'Ã l'achÃ¨vement des travaux. Mandons et ordonnons que la prÃ©sente loi soit insÃ©rÃ©e au MÃ©morial pour Ãªtre exÃ©cutÃ©e et observÃ©e par tous ceux que la chose concerne. Le Ministre des Travaux Publics, Marcel Schlechter Le Ministre chargÃ© du Budget, Jean-Claude Juncker ChÃ¢teau de Berg, le 7 septembre 1987. Jean Doc. parl. no 3113; sess ord. 1986-1987.

Provision text is displayed from LexChat’s stored statute record. Use the official source links to verify amendments, commencement, and current legal force.

About this LexChat collection

Publisher and coverage

LexChat is published by Esheria. Coverage reflects the legislation currently mapped from identified source collections; it may be incomplete, delayed, or later corrected. The official source controls where it differs from this research page.

AI and research method

AI-generated material is explicitly labelled and published only through LexChat's quality controls. It is a research aid, not the source document.

Corrections and reporting

Report a source mismatch, factual issue, personal-data concern, or licensing question to support@esheria.co.ke. Include this page's URL and the supporting official source so the record can be reviewed, corrected, restricted, or withdrawn.

Legal-information disclaimer

LexChat provides legal information and research tools, not legal advice. Verify currency, status, citations, and jurisdiction with authoritative sources and a qualified professional where appropriate.