§ 52-143. Obligation of claimant to furnish information to other lien claimant; damages; applicability of section.

A prime contractor must give lien-related information on request within 10 days, and other lien claimants must give related contractor information within 5 days. A failure to provide the information can result in actual damages or $200 liquidated damages, and the section applies only when the improvement contract is wi

AI-assisted research synopsis — verify against the official legal text below.

Jurisdiction: United States — Nebraska
Instrument: Act or statute
Version: Undated source snapshot
Language: en
Updated: 12 Jul 2026
Official source: View official record ↗

contracting information disclosure liens

Publicly available, excluded from search-engine indexing

This page remains available for direct access and API use, but this release emits noindex,follow for the following reason:

The record does not meet this release's canonical indexing criteria. (market-indexing-disabled)

Statute overview

About this statute

Read the provisions Ask with citations

Search within this statute

Search all stored provisions in this version.

Legal text

Provisions of § 52-143. Obligation of claimant to furnish information to other lien claimant; damages; applicability of section.

Showing 1 of 1

§
§ 52-143. Obligation of claimant to furnish information to other lien claimant; damages; applicability of section.
Verify source ↗

AI-assisted research summary: A prime contractor must give lien-related information on request within 10 days, and other lien claimants must give related contractor information within 5 days. A failure to provide the information can result in actual damages or $200 liquidated damages, and the section applies only when the improvement contract is with a protected party.

(1) A prime contractor, on request, is obligated to furnish the following information within a reasonable time, not exceeding ten days, to any person entitled to claim a lien through him or her: (a) A description of the real estate being improved sufficient to identify it; (b) The name and address of the contracting owner with whom the prime contractor contracted; and (c) Whether there is a surety bond and, if so, the name of the surety. (2) At the request of any person who may claim a lien through him or her, any claimant other than a prime contractor must furnish, within a reasonable time not exceeding five days, the name of the person who contracted for the furnishing by the claimant of the materials or services in connection with which the lien claim may arise. (3) A person who fails to furnish information as required by this section is liable to the requesting party for actual damages or two hundred dollars as liquidated damages. (4) This section shall apply only when the real estate improvement contract is with a protected party. History: Laws 1981, LB 512, § 19.

Provision text is displayed from LexChat’s stored statute record. Use the official source links to verify amendments, commencement, and current legal force.

About this LexChat collection

Publisher and coverage

LexChat is published by Esheria. Coverage reflects the legislation currently mapped from identified source collections; it may be incomplete, delayed, or later corrected. The official source controls where it differs from this research page.

AI and research method

AI-generated material is explicitly labelled and published only through LexChat's quality controls. It is a research aid, not the source document.

Corrections and reporting

Report a source mismatch, factual issue, personal-data concern, or licensing question to support@esheria.co.ke. Include this page's URL and the supporting official source so the record can be reviewed, corrected, restricted, or withdrawn.

Legal-information disclaimer

LexChat provides legal information and research tools, not legal advice. Verify currency, status, citations, and jurisdiction with authoritative sources and a qualified professional where appropriate.

§ 52-143. Obligation of claimant to furnish information to other lien claimant; damages; applicability of section.

Publicly available, excluded from search-engine indexing

About this statute

Search within this statute

Provisions of § 52-143. Obligation of claimant to furnish information to other lien claimant; damages; applicability of section.

Ask AI about this statute

Sign in to ask AI about this statute