Esheria South Africa Case Law
Sign in
South Africa Source-linked decisions Coverage checked

South Africa Case Law

Search judgments by proposition, citation, court, judge or legal topic, then move directly into the source-grounded case analysis.

Courts on this page
1 court collection
Last checked

Search and filter South Africa case law

Results update automatically as you type.

South Africa decisions

Decisions matching the current search

Clear filters
Commercial And Corporate [2000] ZASCA 7

Martin Harris & Seuns Ovs (Edms) Bpk v Qwa Qwa Regeringsdiens, Qwa Qwa Regeringsdiens v Martin Harris & Seuns Ovs (Edms) Bpk (674/92, 676/92)

Martin Harris & Seuns Ovs (Edms) Bpk v Qwa Qwa Regeringsdiens, Qwa Qwa Regeringsdiens v Martin Harris & Seuns Ovs (Edms) Bpk (674/92, 676/92) [2000] ZASCA 7; 2000 (3) SA 339 (SCA); [2000] 2 All SA 72 (A) (23 March 2000)

Court
Supreme Court of Appeal
Case number
674/92, 676/92
Judges
Nienaber, Hefer, Harms, Marais, Mpati

An appeal over construction delays and a job-work prescription defence failed. The court held the contract’s express remedies excluded damages and the job-work claim had not prescribed.

  • Construction Contracts
  • Mora Creditoris
  • Prescription
  • Contractual Remedies
  • Delay And Disruption
  • Specific Performance
Read case analysis

About this LexChat collection

South Africa decisions are organised by court, judge, legal area and indexed issue so a practitioner can move from a proposition to a citable authority with the surrounding context intact.

Source links and collection timestamps are retained alongside the indexed records.