Esheria Lesotho Case Law
Sign in
Lesotho Source-linked decisions Coverage checked

Lesotho Case Law

Search judgments by proposition, citation, court, judge or legal topic, then move directly into the source-grounded case analysis.

Courts on this page
2 court collections
Last checked

Search and filter Lesotho case law

Results update automatically as you type.

Lesotho decisions

Decisions matching the current search

Clear filters
Construction law [2025] LSHC 197

Condo Construction (PTY) LTD V BRixs Development Company (PTY) LTD (CCT/0379/2024)

Condo Construction (PTY) LTD V BRixs Development Company (PTY) LTD (CCT/0379/2024) [2025] LSHC 197 (14 August 2025)

Court
High Court
Case number
CCT/0379/2024

The High Court of Lesotho granted summary judgment for unpaid construction fees, finding no bona fide defence despite the defendant’s defects allegations.

  • Summary judgment
  • Certificate of completion
  • Contractual obligations
  • Retention monies
  • Acknowledgment of debt
  • Defences to summary judgment
Read case analysis
Construction law [2011] LSCA 13

Tsoelopele Consultants And Contractors (Pty) Ltd v Lesotho Electricity Co. (Pty) Ltd (C of A (CIV) 31 of 10)

Tsoelopele Consultants And Contractors (Pty) Ltd v Lesotho Electricity Co. (Pty) Ltd (C of A (CIV) 31 of 10) [2011] LSCA 13 (20 April 2011)

Court
Court of Appeal
Case number
C of A (CIV) 31 of 10

The Court of Appeal upheld penalties for late completion of electrical works, holding that the contractor failed to seek further extensions or give timely written notice of delay.

  • Liquidated damages
  • Delay in performance
  • Extension of time
  • Penalty clauses
  • Liquidated-damages
  • Construction-delay
Read case analysis

About this LexChat collection

Lesotho decisions are organised by court, judge, legal area and indexed issue so a practitioner can move from a proposition to a citable authority with the surrounding context intact.

Source links and collection timestamps are retained alongside the indexed records.