10 Apr 1996
CHOI KAM CHAN v. WONG WANG BUN
- Citation
- CHOI KAM CHAN v. WONG WANG BUN
- Court
- Court of Appeal
- Case number
- CACV227/1995
By majority the court held the 1994 agreement did not effect a waiver of the defendant's accrued right to claim liquidated damages under the 1993 contract; the plaintiff's withholding of the renovation plans meant the works remained uncompleted for the purposes of the original contract, so the trial judge's assessment on delay was not disturbed and the appeal was dismissed.