2 May 2024
MAHSURIMAS SDN BHD DORSETT REGENCY HOTEL (M) SDN BHD
- Citation
- WA-22C-16-02/2021 (Mahkamah Tinggi)
- Court
- High Court
- Case number
- WA-22C-16-02/2021 (Mahkamah Tinggi)
Court found defendant repeatedly delayed handovers and late‑supplied employer materials, there was no extension‑of‑time clause and defendant's conduct prevented contractor performance so time became at large; defendant's immediate termination without reasonable notice and for mala fide reasons was unlawful; LAD claim invalidated; plaintiff entitled to proven contract balance and nominal loss of profit; defendant entitled only to nominal special damages for its counterclaim.