20 Nov 2025
SENG YOON SENG HOLDINGS SDN. BHD. JEKS ENGINEERING SDN. BHD.
- Citation
- BA-22NCvC-97-03/2023 (Mahkamah Tinggi)
- Court
- High Court
- Case number
- BA-22NCvC-97-03/2023 (Mahkamah Tinggi)
On the balance of probabilities Plaintiff completed the works and is entitled to RM226,233.74; Plaintiff failed to prove any written application for extension of time as required by the Letter of Award, therefore time remained of the essence and Plaintiff is liable for LAD calculated at RM9,000 per day for 295 days (total RM2,655,000.00); exclusion of LAD from final statement of account did not constitute a waiver or estoppel absent clear intention and reliance; Defendant entitled to proven back charges of RM30,859.86; Plaintiff's claim for solicitor's fees disallowed; interest awarded at 5%…