24 Jun 2020
PRINSIPTEK (M) SDN BHD NAZA TTDI SENTRALIS SDN BHD (formerly known as Ikhlas Murni Sdn Bhd)
- Citation
- WA-22C-115-12/2019 (Mahkamah Tinggi)
- Court
- High Court
- Case number
- WA-22C-115-12/2019 (Mahkamah Tinggi)
Plaintiff's application for an injunction was dismissed because it failed to establish a strong prima facie case of unconscionability: the EoT applications did not satisfy contractual notice requirements or were properly assessed by the Architect, the Plaintiff omitted material disclosure (winding‑up petition) in ex‑parte proceedings, and the balance of convenience favored the Defendant given the on‑demand nature of the bond and evidence of project delay attributable to the Plaintiff; costs were awarded to the Defendant.