28 Apr 2025
SEIE ENGINEERING SDN BHD Kerajaan Malaysia
- Citation
- WA-21C-5-08/2022 (Mahkamah Tinggi)
- Court
- High Court
- Case number
- WA-21C-5-08/2022 (Mahkamah Tinggi)
Although the Plaintiff was deemed to have accepted the NSC nomination by not objecting within 21 days and the contract places primary responsibility for NSC defaults on the contractor, the Court found on evidence that material delays were also caused by design changes/requirements from the end user (MOH) and by the Defendant's failure to issue CMGD timely; JKR wrongly issued CNC No.2 and failed to decide on EoT No.8; as a result Plaintiff was entitled in part to its claimed losses and variations and was awarded RM18,155,150.80 with interest and costs, while the Defendant's back-charge for TNB…