13 May 2010
WING HONG CONSTRUCTION LTD v. TIN WO ENGINEERING CO LTD
- Citation
- WING HONG CONSTRUCTION LTD v. TIN WO ENGINEERING CO LTD
- Court
- Court of First Instance
- Case number
- HCCT13/2010
The court refused leave to appeal because, applying the 'obviously wrong' standard, the arbitrator was entitled to infer a completion date from the works programme despite lack of formal notification and was entitled to construe the ambiguous phrase 'rate of works' in SSC 24 so as not to bar recovery of prolongation costs; those conclusions were not obviously wrong.