15 Aug 2005
CHUN WO FOUNDATION LTD v. DORRO PROPERTIES LTD
- Citation
- CHUN WO FOUNDATION LTD v. DORRO PROPERTIES LTD
- Court
- Court of First Instance
- Case number
- HCCT84/2000
The court found the piling works were substantially complete by 31 January 2000, the architect and BA certifications made payment obligations due, Dorro was not entitled to liquidated damages (time was effectively at large or excused by employer/BA acts) and Dorro failed to prove on the balance of probabilities that the piles were out of tolerance in a way that caused remedial works and loss; therefore judgment entered for plaintiff for the certified sums plus interest and the counterclaim dismissed.